By accessing and using the Sreevaas Smart Infra Developers website and services, you accept and agree to be bound by these Terms and Conditions. If you do not agree to these terms, please do not use our website or services.
We reserve the right to modify these terms at any time. Changes will be effective immediately upon posting on this page. Your continued use of our website constitutes acceptance of any modifications.
Sreevaas Smart Infra Developers provides custom home construction, interior design, renovation, and architecture services. The scope, timeline, and cost of each project will be defined in a separate agreement or contract between Sreevaas Smart Infra Developers and the client.
All services are subject to availability and we reserve the right to refuse service to anyone for any reason at any time.
Payment terms will be outlined in each individual project contract. Generally, payments are made in stages corresponding to project milestones. Late payments may result in project delays and may incur additional charges as specified in the contract.
All quoted prices are valid for 30 days from the date of the quote unless otherwise specified. Prices may be subject to change due to fluctuations in material costs or regulatory changes.
All content on this website, including text, graphics, logos, images, and software, is the property of Sreevaas Smart Infra Developers and is protected by intellectual property laws. You may not reproduce, distribute, or create derivative works without our express written permission.
Designs and plans created for clients remain the intellectual property of Sreevaas Smart Infra Developers unless otherwise agreed upon in writing.
Sreevaas Smart Infra Developers shall not be liable for any indirect, incidental, special, consequential, or punitive damages resulting from your use of or inability to use our services. Our total liability shall not exceed the amount paid by you for the specific service giving rise to the claim.
We are not responsible for delays caused by factors beyond our reasonable control, including but not limited to natural disasters, government actions, or supply chain disruptions.
These Terms and Conditions shall be governed by and construed in accordance with the laws of India. Any disputes arising under these terms shall be subject to the exclusive jurisdiction of the courts in Noida, Uttar Pradesh.
If you have any questions about these Terms and Conditions, please contact us: